Terms and Conditions

Couple cheering in front of a house, arms raised, smiling. Bright sunny day.

Last Updated: February 19, 2026


1. Agreement to Terms

By accessing and using this website, you agree to comply with these Terms and Conditions. If you do not agree, please do not use the website.


2. Services Disclaimer

Lucero Construction LLC provides residential remodeling services in Huntington Beach and surrounding Orange County communities.


Information on this website is for general informational purposes only and does not constitute a binding construction contract.


All remodeling projects require a separate written agreement.


3. Licensing

Lucero Construction LLC operates under:


California General Contractor License #1082093


License information may be verified through the California Contractors State License Board (CSLB).


4. Estimates & Quotes

  • Complimentary quotes are provided following consultation.
  • Estimates are subject to change based on site conditions, material availability, scope modifications, and permitting requirements.
  • A written contract must be signed before work begins.


5. Payment Terms

Payment schedules, deposits, and progress payments will be outlined in the formal construction agreement in compliance with California contractor law.


6. Project Timelines

Timelines provided are estimates and may be affected by:

  • Permit approval delays
  • Material availability
  • Weather conditions
  • Change orders
  • Unforeseen structural conditions

Lucero Construction LLC is not liable for delays beyond reasonable control.


7. Intellectual Property

All website content, including:

  • Text
  • Logos
  • Images
  • Project descriptions
  • Layout

are the property of Lucero Construction LLC and may not be copied, reproduced, or distributed without written permission.


8. Limitation of Liability

To the fullest extent permitted by California law:

  • The website is provided "as is."
  • We do not guarantee uninterrupted or error-free access.
  • Lucero Construction LLC shall not be liable for indirect, incidental, or consequential damages arising from website use.


9. No Warranty on Website Content

While we strive for accuracy, website information may contain errors or outdated details. Service availability and scope may change.


10. Third-Party Links

We are not responsible for third-party websites linked through our site, including social media platforms.


11. Governing Law

These Terms and Conditions are governed by the laws of the State of California.


Any disputes shall be resolved in the courts of Orange County, California.


12. Changes to Terms

We reserve the right to update these Terms and Conditions at any time. Continued website use constitutes acceptance of any changes.


13. Contact Information

Lucero Construction LLC

10442 Crawford Canyon Rd, Santa Ana, CA 92705

Phone: (714) 605-9490
Email: iluceroconst@gmail.com